TERMS AND CONDITIONS OF TRADE
Thank you for choosing The Little Printer (The Little Printer, we, us, our) as your design and print service provider. By engaging The Little Printer to provide the Services, you agree to be bound by the following terms and conditions (Terms). The Terms set out how we will work together to deliver your design goals. These Terms apply exclusively to the Services provided by us, our employees and our agents and we may change these terms at any time by written notification.
1. ENGAGEMENT
1.1. Project Brief
1.1.1. We will collaborate and consult with you to prepare the Project Brief based on the needs, wishes and instructions you communicate with us.
1.1.2. The Project Brief will contain the following information:
1.1.2.1. a clear description of the Services to be performed by The Little Printer;
1.1.2.2. a quote for the Project Fees;
1.1.2.3. the Final Works to be produced including the Approved Format; and
1.1.2.4. any other information or instructions that a Supplier may require to print the Final Works in the Approved Format including the quantity required, packaging instructions and materials.
1.1.3. We will work with you to ensure we receive acceptance of the Project Brief prior to commencing the Services.
1.1.4. For the avoidance of doubt, the Project Brief (including the Project Fees) are deemed to have been approved by you when The Little Printer receives your written confirmation and/or you pay the Deposit.
1.1.5. You acknowledge that the Deposit is non-refundable save for the circumstances specified at clause 4.
1.2. Cancellation or Variation of the Project Brief
1.2.1. If you choose to withdraw or cancel the Project Brief, this must be expressly communicated in writing and The Little Printer may charge you a Cancellation Fee.
1.2.2. If you request to change or update the Project Brief before the Delivery Date, The Little Printer may charge Additional Fees.
1.2.3. We are not obliged to undertake any variation of or change to the Project Brief and/or Works under clause 1.2.2.
1.3. Quote for Project Fees
1.3.1. The quote for the Project Fees:
1.3.1.1. is an estimate only, and may vary depending on changes to the Project Brief;
1.3.1.2. is non-transferable; and
1.3.1.3. may be withdrawn or amended upon our written notice.
1.3.2. Unless otherwise agreed by the Parties and subject to any variation of the Project Brief, the Project Fees are inclusive of all Services under the Project Brief including:
1.3.2.1. the Design Services and Printing Services; and
1.3.2.2. delivery of the Final Works where specified.
1.3.3. The Project Fees do not include third party disbursements or payments for the inclusion of Third Party Materials in the Works. We will notify you of any third-party fees before these are incurred.
2. SERVICES
2.1. Provision of Services
2.1.1. The Little Printer will provide the Services in accordance with these Terms.
2.1.2. You acknowledge and agree that the Printing Services will be subcontracted to Suppliers approved by The Little Printer.
2.2. Design Services
2.2.1. Once the Deposit is paid and you have approved the Project Brief, The Little Printer will commence the Design Services.
2.2.2. All Works developed as part of the Design Services are created to the best of our ability to meet your needs in the Project Brief.
2.3. Preliminary Works
2.3.1. The Little Printer will deliver the Preliminary Works in accordance with the Project Brief.
2.3.2. You will review the Preliminary Works to determine if the Preliminary Works meet the Project Brief.
2.3.3. All Revisions must be communicated in writing by you. You must deliver your feedback on the Preliminary Works (any notify us of any Revisions) within fourteen (14) days of receipt so we can keep to the Delivery Date.
2.3.4. The Little Printer will revise the Preliminary Works in accordance with your feedback and perform Revisions that are within the scope of the Project Brief.
2.3.5. If The Little Printer reasonably forms the view that the extent of the Revisions requested under clause 2.3.4 are beyond the scope of the Project Brief, The Little Printer may charge an Additional Fee.
2.3.6. The Parties will continue the process set out in clause 2.3.1 to 2.3.5 above until:
2.3.6.1. you approve a Preliminary Work as a Final Work; or
2.3.6.2. you or The Little Printer decide to end the Design Services by providing written notification to the other party.
2.3.7. If you decide not to proceed with the Design Services under clause 2.3.6.2, you are not entitled to a refund of the Deposit and a Cancellation Fee will apply.
2.4. Approval of Final Works
2.4.1. You must confirm your approval of a Final Work where the Final Work reasonably complies with the Project Brief within fourteen (14) days of receiving the Final Works unless otherwise agreed.
2.4.2. While we will take all care in preparing the Final Works, you are responsible for proofreading and identifying any Errors or Revisions prior to granting your approval. You are liable for any Errors or Revisions that exist in the approved Final Work.
2.4.3. If The Little Printer reasonably forms the view that the extent of the Revisions requested under clause 2.4.2 are beyond the scope of the Project Brief, The Little Printer may charge an Additional Fee.
2.4.4. When you have confirmed your acceptance of a Final Work, the Design Services are deemed complete and we will deliver the Final Works to you in the Approved Format in accordance with the Project Brief and the Delivery Date.
2.4.5. The Little Printer is not responsible for performing Revisions to the Final Works in the Approved Format that:
2.4.5.1. extend beyond the scope of the Project Brief;
2.4.5.2. were not identified by you before the Final Work was approved; and
2.4.5.3. were caused by anyone other than The Little Printer.
2.4.6. Following your approval of the Final Works, you must return all copies of Preliminary Works in your possession or control to us.
2.5. Printing Services
If you require Printing Services, you acknowledge that once submitted for Printing, a request for Printing Services cannot be altered or cancelled.
2.6. Colour Variations
2.6.1. The Printing of the Final Work may vary in colour between a Final Work as displayed on a computer screen or mobile device and a Final Work produced in the Approved Format.
2.6.2. The Little Printer has no liability for colour variation in Final Works resulting from the Printing Services providing the Final Works reasonably meets the Project Brief
3. DELIVERY OF FINAL WORKS
3.1. Delivery Date
3.1.1. We will use our best efforts to meet the Delivery Date set out in the Project Brief.
3.1.2. We will notify you of any expected delay and the Project Brief will be updated to reflect any agreed changes to the Delivery Date.
3.1.3. You acknowledge and agree that outside factors may impact on us meeting the Delivery Date including delays by Suppliers and by you providing feedback on Preliminary Works. We will not be liable for any deadlines which are not met due to circumstances beyond our control, such as Supplier turnaround, illness, injury or a delay in you providing instructions or confirming your approval of the Final Works.
3.1.4. We may refuse to deliver the Final Works or rescind any orders if you are in breach of these Terms.
3.2. Replacement of Final Works
We will retain and archive digital copies of The Final Works for a minimum of six (6) months following the Delivery Date. If you request replacement digital files of a Final Work and these are available for resupply, The Little Printer may charge a Replacement Fee at our complete discretion.
4. REFUNDS
The Little Printer will return the Deposit where The Little Printer cancels the Services or the parties cannot agree on the scope of the Project Brief, provided The Little Printer has not commenced the Services.
5. INTELLECTUAL PROPERTY
5.1. Ownership of Works
5.1.1. The Little Printer respects Intellectual Property Rights and expects the same of you. This clause sets out what you own and what we own, and how the Works can be used.
5.1.2. The Little Printer is the first author and owner of all Intellectual Property Rights (including copyright and other statutory and common law rights) subsisting in the Preliminary Works and the Final Works, subject to the inclusion of Third Party Materials.
5.2. Licence to Final Works
5.2.1. In consideration and upon full payment of the Project Fee, The Little Printer grants you an exclusive, non-sub-licensable, non-transferable and non-assignable licence to use the Final Works for the Purpose.
5.2.2. Subject to clause 5.10, in granting the licence set out at clause 5.2.1 above, The Little Printer consents to the Final Works being:
5.2.2.1. stored electronically on your server or computer network;
5.2.2.2. used, reproduced, distributed, communicated or published by you;
5.2.2.3. subject to these Terms, printed by third party suppliers; and
5.2.2.4. used as allowable under the Copyright Act 1978 (Cth).
5.2.3. You must not alter, modify or adapt the Final Works in any way beyond the scope allowable under these terms and the Project Brief without our express written consent.
5.2.4. Unless otherwise specified in the Project Brief, we will not release Raw Files or files used by the Supplier in the course of the Printing Services.
5.3. Ownership of Preliminary Works
5.3.1. The Little Printer retains all Intellectual Property Rights in the Preliminary Works.
5.3.2. You are not permitted any use of the Preliminary Works and you agree to keep the Preliminary Works confidential.
5.3.3. You acknowledge and agree that The Little Printer may use, commercialise and/or deliver any or all Preliminary Works to other clients.
5.4. Assignment Requests
You may request the assignment of the Final Works any time by submitting a written request to The Little Printer. The Little Printer will agree to an assignment in its absolute discretion and we reserve the right to apply an Additional Fee. Following an assignment, you will own the Final Works and will be able to use, amend and reconfigure the Final Works as you see fit, subject to any Third Party Material.
5.5. Assistance
Each Party will do such further acts and execute such further documents and instruments as are necessary to protect the Final Works and carry out its obligations under this Agreement.
5.6. Third Party Materials
5.6.1. The Little Printer may include Third Party Materials in the Final Works.
5.6.2. The Little Printer will inform you of any Third-Party Materials that are incorporated into the Final Works and of any need to license (at your expense) the Third-Party Materials to enable you to use and distribute the Final Works for the Purpose. If you fail to secure the necessary licences, you indemnify us from and against all damages, liabilities, costs, losses or expenses arising out of any claim by a third party in relation to that failure.
5.6.3. Where the Final Works contain Third Party Materials, you must not:
5.6.3.1. remove any copyright, trade mark or other proprietary notices pertaining to Third Party Materials from any portion of the Final Works; and
5.6.3.2. reproduce, modify, prepare derivative works based upon, distribute, license, lease, sell, resell, transfer, publicly display, publicly perform, transmit, stream broadcast or otherwise exploit the Third-Party Materials as separate to the Final Works.
5.7. Client Materials
5.7.1. If you provide us with Client Material, you grant to The Little Printer a royalty-free, non-exclusive, non-transferable and revocable licence to the Intellectual Property Rights subsisting in the Client Materials only as necessary to carry out the Services.
5.7.2. You warrant that:
5.7.2.1. you own the Intellectual Property Rights in the Client Materials, or that you have procured any necessary third-party licence approvals to enable The Little Printer to use the Client Materials in the Final Works; and
5.7.2.2. the Client Materials will not infringe the Intellectual Property Rights of any third party.
5.7.3. When you provide Client Materials for inclusion in the Preliminary Works or Final Works, you are responsible for retaining a backup. We will not be responsible for the loss of or damage to any Client Materials that you submit.
5.7.4. The Little Printer will not reproduce or use the Client Materials in any other project without your written consent.
5.8. Marketing
We are proud of our Services and our clients and want to promote them. You permit The Little Printer to use samples of the Final Works and your name and identity as part of our portfolio, for the purposes of
promoting and advertising the business of The Little Printer. You may withdraw your consent at any time by submitting a written request to The Little Printer.
5.9. Third Party Infringement
To the best of The Little Printer’s knowledge, the Final Works will not infringe the Intellectual Property Rights of a third party and, subject to clause 5.6, no third party shall have any right or entitlement to restrict your use, reproduction or modification of the Final Works. However, The Little Printer does not make any warranty that the Final Works do not infringe third party Intellectual Property Rights inadvertently or by coincidence. The Little Printer has not conducted clearances with respect to your ability to use, apply or distribute the Final Works including as a brand or trade mark.
5.10. Moral Rights
5.10.1. The Little Printer together with its staff assert its right to be identified as the author(s) of all Works and The Little Printer’s staff do not waive any of their Moral Rights in any Works that are created for you under the Project Brief.
5.10.2. You must attribute all Work to The Little Printer to the extent that the Work is of a type where attribution can reasonably be given or as agreed by the Parties.
6. CONFIDENTIALITY
6.1. The Parties acknowledge that during their engagement, each Party may grant the other access to its Confidential Information and materials.
6.2. The Parties agree to:
6.2.1. maintain the confidential nature of the disclosing Party’s Confidential Information unless strictly required otherwise by law;
6.2.2. limit access to Confidential Information to employees, officers or representatives who have a need to know for carrying out its obligations under these Terms and who are bound by the same confidentiality obligations as set out in this clause;
6.2.3. at least use the same efforts to protect the disclosing Party’s Confidential Information as it uses to protect its own proprietary information;
6.2.4. not use the Confidential Information in any way which would be harmful to the best interests of the disclosing Party; and
6.2.5. only use Confidential Information to the extent necessary to perform its obligations under the Project Brief.
6.3. The obligations in this clause 6 survive the termination of your engagement with The Little Printer.
7. INVOICES AND PAYMENT
7.1. Project Fees
7.1.1. Unless otherwise agreed, you agree to pay the Deposit set out in the Project Brief on receipt of a valid tax invoice in accordance with the Payment Terms.
7.1.2. The balance of the Project Fees will be paid on delivery of the Final Works in the Approved Format in accordance with the Payment Terms.
7.2. Additional Fees
7.2.1. The Little Printer will charge Additional Fees as they become payable from time to time and at its complete discretion including for:
7.2.1.1. a change in the timing or complexity of the Design Services or Printing Services;
7.2.1.2. providing you with services beyond the scope of the Project Brief;
7.2.1.3. additional expenses to deliver the Works; and
7.2.1.4. any delay in complying with obligations under this Agreement if the delay is a direct or indirect result of any act of omission by you or a third party.
7.2.2. You agree to pay Additional Fees in accordance with the Payment Terms.
7.3. Failure to Pay
7.3.1. If you fail to pay an invoice issued in accordance with this Agreement, including an invoice for Additional Fees, The Little Printer reserves the right to:
7.3.1.1. charge a Late Fee for every fourteen (14) days an invoice remains outstanding;
7.3.1.2. suspend all Design Services or Printing Services until all overdue invoices are paid; and/or
7.3.1.3. withhold the Delivery of Final Works until all overdue invoices are paid.
7.3.2. You agree to cooperate fully with The Little Printer with respect to the resolution of any outstanding invoice under this clause 7.3.
7.4. No Set Off
You may not offset any of the Project Fees payable to The Little Printer under this Agreement against any monies you may consider The Little Printer owes you.
8. WARRANTIES
8.1. The Little Printer warrants that:
8.1.1. except for the Third-Party Material and Client Materials, The Little Printer has a right to assign or otherwise licence the use of all the Intellectual Property Rights in the Final Works in accordance with these Terms;
8.1.2. except for the Third-Party Material and the Client Materials, the Final Works are original; and
8.1.3. subject to this Agreement, the Final Works do not infringe the rights of any third party.
8.2. By engaging The Little Printer to perform the Services, you represent and warrants that:
8.2.1. you will perform and observe all of your obligations under these Terms;
8.2.2. The Little Printer may immediately and temporarily suspend the Services and access to the Final Works if The Little Printer forms the reasonable view that you are in breach of these Terms;
8.2.3. if there is delay in The Little Printer performing a Service or delivering the Final Works, you will meet with The Little Printer to discuss the best way to rectify the delay without penalty;
8.2.4. you have the right to grant a licence in the Client Materials; and
8.2.5. you will pay all Project Fees, Additional Fees and other charges under these Terms as and when they become payable.
9. REPRESENTATIONS
9.1. To the extent permitted by law, The Little Printer makes no representation that the Work is fit for any expressed or implied intended use or is suitable for your future projects.
9.2. You acknowledge that the Final Works are designed to be used and reproduced in the Approved Format. The efficacy of The Little Printer’s technical advice (if any) regarding the use of the Final Works may be affected by the particular application of and the circumstances in which the Work is used. It is entirely your responsibility to assess the suitability of the Final Work for your intended processes and uses and consequences of using the Final Work in any format other than the Approved Format or any manner not specifically contemplated by The Little Printer’s technical advice.
9.3. You unconditionally release The Little Printer from all claims (of any kind or nature) arising as a result of or in respect of the particular application of the Works or the uses of the Work in the circumstances described above.
10. LIMITATION OF LIABILTY
10.1. To the extent permitted by law, The Little Printer accepts no liability for carrying out the Services including any loss of profits or consequential loss arising directly, indirectly, as a consequence of or in connection with these Terms.
10.2. To the extent that The Little Printer is not able to limit its liability under these Terms, The Little Printer’s liability is limited, at The Little Printer’s option to either replacing any Final Work with another or substitute Final Work or refunding the Project Fees payable for that Final Work.
10.3. If you are a consumer under the Australian Consumer Law, the goods provided under this Agreement come with guarantees that cannot be excluded under the Australian Consumer Law. You are entitled to a replacement or refund for a major failure and compensation for any other reasonably foreseeable loss or damage. You are also entitled to have the goods repaired or replaced if the goods fail to be of acceptable quality and the failure does not amount to a major failure.
11. CLIENT INDEMNITY
You will continually indemnify The Little Printer, our employees, officers and agents from and against:
11.1. any claim made against The Little Printer that the Client Materials included in the Final Works infringes the Intellectual Property Rights of a third party; and
11.2. all claims in respect of any loss, damage or injury (of any kind or cause) (including legal costs) that The Little Printer may sustain as a result of or arising out of your acts and omissions in performing or failing to perform your obligations under these Terms.
12. TERMINATION
12.1. Either Party may terminate the Services with the written consent of the other Party.
12.2. The Little Printer may immediately terminate our engagement with you if:
12.2.1. the Parties fail to agree on the scope of the Project Brief;
12.2.2. you fail to pay Project Fees or Additional Fees within fifteen (15) days of that amount being due;
12.2.3. you request Revisions to Works that are beyond the scope of the Project Brief and/or you decline to pay Additional Fees;
12.2.4. you do not approve Preliminary Works;
12.2.5. there is a claim that the Client Materials infringe the Intellectual Property Rights of a third party;
12.2.6. you neglect or fail to observe or perform any of your obligations (expressed or implied) under these Terms;
12.2.7. we form the reasonable view that you are in breach of these Terms and you do not remedy the breach within fourteen (14) days of our written notification of the breach; or
12.2.8. you commit an act of bankruptcy or insolvency or your business is declared bankrupt or wound-up or has a trustee, liquidator, administrator, receiver or manager appointed under the Bankruptcy Act 1968 or Corporations Act 2001 (as applicable).
12.3. Consequences of Termination
Where the engagement between the Parties is terminated, the following applies:
12.3.1. The Little Printer may immediately stop all Services;
12.3.2. The Little Printer is entitled to receive and retain:
12.3.2.1. the Deposit; and
12.3.2.2. payment for all work done up to the date of termination calculable in accordance with the Hourly Rates or any milestone payments specified in the Project Brief including any expenses,
12.3.3. the Parties must immediately stop all use of the other’s Confidential Information that may have been made available under these Terms;
12.3.4. you must stop using and return all copies of Works in your possession or control to The Little Printer;
12.3.5. you must immediately cease holding yourself out or representing yourself as a customer of The Little Printer; and
12.3.6. the Parties are immediately released from their obligations under these Terms except those obligations in clause 5-8 ,10, 11 and 12.
13. MISCELLANEOUS
13.1. In the event of any conflict or inconsistency in the Terms, the order of precedence for its interpretation is as follows: the Project Brief, followed by the Terms.
13.2. The Little Printer may assign or permit a third party to obtain the benefit of our rights and interest under these Terms without your prior written consent. You must not assign or permit a third party to obtain the benefit of your rights and interest under these Terms unless you obtain our prior written consent.
13.3. These Terms are governed by and construed in accordance with the laws of Victoria, Australia. The Parties submit to the exclusive jurisdiction of the courts of the State of Victoria.
13.4. These Terms and the Project Brief constitute the sole and entire agreement between the Parties and no warranties, representations, guarantees or other terms of any nature not recorded therein will be of any force or effect.
13.5. If any of these terms is invalid and not enforceable, all other terms which are self-sustaining and capable of separate enforcement without regard to the invalid provisions will be and continue to be valid and enforceable in accordance with those terms.
14. DEFINITIONS
In these Terms the words in this clause 14 will have the following meanings unless the context requires otherwise:
14.1. Approved Format means the digital and/or print format in which The Little Printer has agreed to produce, publish or otherwise deliver the Final Works as outlined in the Project Brief;
14.2. Additional Fee means a fee for any additional products and/or Services provided by The Little Printer under these Terms including any Cancellation Fees, any Late Fees, any Replacement Fees, the inclusion of any Third Party Materials in a Preliminary Work or Final Work, or an agreed variation to the Project Brief under clause 1.2.2.
14.3. Cancellation Fee means a fee for the cancellation or withdrawal of the Project Brief by you, calculated pro rata for the time spent performing the Services up until the date of cancellation or withdrawal, in accordance with the Hourly Rates together with any expenses or disbursements incurred;
14.4. Client Material means any supplementary materials created or delivered to The Little Printer for inclusion in, or use in connection with, the creation of the Work including (but not limited to) photographs, illustrative works including logos and product labels, fonts or literary works;
14.5. Confidential Information means all unpatented inventions, ideas, know-how, concepts, trade secrets, processes, techniques, software, products, and any and all other unregistered or unpatented Intellectual Property Rights, financial and business information of a disclosing party which the disclosing party regards as confidential to it, which is evidence by its nature to be confidential or is identified as being confidential, and all copies, notes, records and all related information generated by a party based on or arising out of such disclosure.
Confidential Information exclusives, or as the case requires, ceases to include information which is:
14.5.1. available to the public at or after the date of its disclosure to the receiving party from sources other than the receiving party;
14.5.2. at the date of its disclosure to the receiving party is already known by the receiving party otherwise than by prior confidential disclosure from the disclosing party; or
14.5.3. demonstrated by the receiving party to be independently developed by an employee or agent of the receiving party having no knowledge of such information which is the subject of the disclosure;
14.6. Delivery Date means the date for the delivery of Final Works by The Little Printer as initially set out in the Project Brief or otherwise varied by The Little Printer from time to time;
14.7. Deposit means a fifty per cent (50%) deposit of the total Project Fees payable under the Project Brief or such other upfront payment agreed by the Parties in writing, on receipt of a valid tax invoice;
14.8. Design Services means the multimedia and graphic design services to be performed by The Little Printer in accordance with these Terms and as further described in a Project Brief;
14.9. Errors mean typographical errors, spelling mistakes or incorrect information in a Work;
14.10. Final Works means Works to be delivered by The Little Printer that have been approved by you and that comply with the Project Brief, but does not include the Preliminary Works;
14.11. Hourly Rate means the amount of money charged by The Little Printer per hour as specified in the Project Brief;
14.12. Intellectual Property Rights means all rights relating to copyright, neighbouring rights, trade marks (registered and unregistered), designs, all rights in relation to inventions (including patent rights), and any other rights resulting from intellectual activity in the industrial, scientific, literary or artistic fields;
14.13. Late Fee means a fixed fee of AUD $66.00 plus GST for every fourteen (14) days an invoice remains outstanding or such other fee determined by The Little Printer;
14.14. Moral Right means a right of attribution of authorship, a right not to have authorship falsely attributed, a right of integrity of authorship, or a right of a similar nature which is conferred by the Copyright Act 1968 (Cth) and which exists or come to exist anywhere in the world in a deliverable form comprised within these Terms;
14.15. Payment Terms means the terms upon which you will pay the Project Fees including the Deposit and Additional Fees, being thirty (30) days from receipt of a valid tax invoice from or as otherwise specified in The Project Brief;
14.16. Purpose means the purpose identified in the Project Brief or otherwise the direct and limited application for which the Final Works have been created;
14.17. Preliminary Works means proofs, concepts, sketches, working files, visual presentations, designs and documents (in any format) which may or may not be shown and/or delivered to you for consideration excluding Third Party Material and the Final Works;
14.18. Printing Services means the production and/or manufacture of Final Works in the Approved Format as further described in a Project Brief; Printing has a similar meaning;
14.19. Project Brief means the set of criteria for the completion of the Services as agreed by the Parties including the information specified at 1.1.2;
14.20. Project Fees mean the itemised payments for the provision of Services and the Delivery of the Final Works by The Little Printer under the Project Brief;
14.21. Raw Files means original, unprocessed and unedited design content used by The Little Printer in the creation of the Works;
14.22. Replacement Fees means a fee of AUD $55.00 plus GST per file or such other fee determined by The Little Printer from time to time at our sole discretion for the replacement of digital or electronic copies of the Final Work under these Terms;
14.23. Revisions mean the rectification of inconsistencies in the composition, style or presentation of the Work that result in a Work not substantially complying with the Project Brief, quote or engagement documentation;
14.24. Services means the Design Services and the Printing Services;
14.25. Supplier means the third-party providers delivering the Printing Services;
14.26. Terms means these terms and conditions;
14.27. Third-Party Material means any material created by a third party and is included in the Works;
14.28. Works means all Preliminary Works, Final Works and all other products, materials designs, artwork, layout, photographs and literary or other artistic works as defined in the Copyright Act 1968 (Cth) to be created by The Little Printer in accordance with the Project Brief, quote or engagement documentation, together with Third-Party Material or Client Material; and
14.29. You means the person or entity who engages The Little Printer to perform the Services and for whom The Little Printer creates the Works.
15. INTERPRETATION
In these Terms, except to the extent that the context otherwise requires:
15.1. Words denoting the singular include the plural and vice versa;
15.2. Words denoting individuals or persons include bodies corporate and trusts and vice versa;
15.3. Reference to a clause, paragraph or schedule is a reference to a clause, paragraph or schedule of these terms;
15.4. Headings are included for convenience only and will not affect the interpretation of these Terms or any schedule;
15.5. Words denoting any gender includes all genders; and
15.6. where a word or phrase is given a definite meaning in these Terms as part of speech or other grammatical form for that word or phrase has a corresponding meaning.